Article Date: 07/29/2012


Delay Claim Hindered by Failure to Update Schedule


Armed Services Board of Contract Appeals

 

Appeal of Hedgecock Electric, Inc.

 

No. 56307
June 20, 2012



Overview

 

A contractor's failure to update its schedule on a monthly basis, as required by the contract, hindered its ability to prove the impact of government-caused delay on the project's critical path. Daily job reports were used instead.

 

Background

 

The Navy awarded ... Log in to view the full text.

 



NOT YET A SUBSCRIBER?

Purchase a Subscription
with a money-back guarantee
and immediate access

OR

Buy This Item Individually
Price: $20.00


Already a member?

Email:  

Password:  











WPL
PUBLISHING CO, INC.
WPL Publishing - 5750 Bou Avenue #1712 - Rockville, MD 20852

Phone: (301)765-9525  -  Fax: (301)983-4367

All Content and Design Copyright © 2024 WPL Publishing
About Us

Contact Us

Privacy Policy

My Account