Article Date: 08/30/2024

Contractor Allowed Time Extension for Float Time Delay

Appellate Court of Maryland

9103 Basil Court Partners, LLC v. Monarc Construction, Inc.

Case no.: 2236, 2238, Sept. Term 2022

Date filed: August 15, 2024

Overview

A Maryland appeals court has allowed a contractor a time extension for owner-caused delays that were not on the schedule’s critical path. The ruling came in the context of refusal ... Log in to view the full text.

NOT YET A SUBSCRIBER?

Purchase a Subscription
with a money-back guarantee
and immediate access

OR

Buy This Item Individually
Price: $20.00

Already a member?

Email: REQUIRED

Password: REQUIRED

Forgot your password? Click here to have your password emailed to you.