Article Date: 11/30/2021

Contractor Recovers Extended Field Overhead but Not Home Office Overhead

Armed Services Board of Contract Appeals

Appeal of WECC, Inc.

Case no.: 60949

Date filed: October 19, 2021

Overview

The Armed Services Board of Contract Appeals awarded a contractor extended field office overhead incurred as a result of government-caused delay to work on the schedule’s critical path. However, the contractor was denied unabsorbed home office overhead ... Log in to view the full text.

NOT YET A SUBSCRIBER?

Purchase a Subscription
with a money-back guarantee
and immediate access

OR

Buy This Item Individually
Price: $20.00

Already a member?

Email: REQUIRED

Password: REQUIRED

Forgot your password? Click here to have your password emailed to you.