Pre- and Post-Construction Schedules Failed to Prove Critical Path

U.S. Court of Federal Claims

Ultimate Concrete, LLC v. United States

Case no.:   14-549C

Date filed:  January 10, 2019

Overview

The Court of Federal Claims has ruled that a government-approved pre-construction schedule and a contractor-prepared as-built schedule were not enough, in themselves, to establish the critical path of the schedule during construction.

Background

The International Boundary and ... Log in to view the full text.