Sub Demands Portion of Prime's Claim Settlement with Owner

A settlement agreement between a prime contractor and project owner did not itemize or allocate damages. That did not necessarily mean the settlement amount did not include a subcontractor’s delay damages. The subcontract called for the prime to submit subcontractor delay claims to the owner and pass through any recovery.

The Construction Claims Advisor summary of this case is available to ConstructionPro Network members and includes:

• The citation for the case (case name, case number, and date filed)
• An overview of the case
• Background information about the case
• A summary of the ruling
• A summary of the court’s conclusion and the resulting outcome
• Editor's commentary
• A link to the complete PDF copy of the original opinion