Article Date: 11/29/2004

NOTICE FAILURE DEFEATS SUBCONTRACTOR'S DELAY CLAIM

North Carolina Court of Appeals

American National Electric Corp., Plaintiff, v. Poythress Commercial Contractors and Brown & Jones Architects, Inc., Defendants

No: COA03-794
November 16, 2004

Background

Poythress Commercial Contractors, Inc. was the general contractor on the Cary Fire Station No. 6 project and American National Electric Corporation (ANE) was an electrical subcontractor. Poythress provided a CPM (critical path method) schedule to ANE ... Log in to view the full text.

NOT YET A SUBSCRIBER?

Purchase a Subscription
with a money-back guarantee
and immediate access

Already a member?

Email: REQUIRED

Password: REQUIRED

Forgot your password? Click here to have your password emailed to you.