Delay Claim Hindered by Failure to Update Schedule

Armed Services Board of Contract Appeals

Appeal of Hedgecock Electric, Inc.

No. 56307
June 20, 2012

Overview

A contractor's failure to update its schedule on a monthly basis, as required by the contract, hindered its ability to prove the impact of government-caused delay on the project's critical path. Daily job reports were used instead.

Background

The Navy awarded ... Log in to view the full text.