Armed Services Board of Contract Appeals
Appeal of WECC, Inc.
Case no.: 60949
Date filed: October 19, 2021
The Armed Services Board of Contract Appeals awarded a contractor extended field office overhead incurred as a result of government-caused delay to work on the schedule’s critical path. However, the contractor was denied unabsorbed home office overhead ... Log in to view the full text.