“No-Damage-for-Delay” Clause Ruled Unenforceable

Commonwealth Court of Pennsylvania

Ernest Bock & Sons, Inc. v. City of Philadelphia

Case no.:   349 C.D. 2018

Date filed:  August 12, 2020

Overview

A Pennsylvania appellate court has ruled that a contractor was entitled to delay/acceleration costs despite a “no-damage-for-delay” clause in the contract and the absence of critical path analysis.

Background

The City of Philadelphia awarded ... Log in to view the full text.