Contribution to Late Completion Precluded Assessment of Liquidated Damages

Court of Appeals of Tennessee

E Solutions for Buildings, LLC v. Knestrick Contractor, Inc.

Case no.:    M2018-02028

Date filed:  October 30, 2019

Overview

A Tennessee appeals court has ruled that a contractor could not assess liquidated damages against a subcontractor because the contractor had contributed to the delays causing late completion. This would be the ... Log in to view the full text.