Lack of Critical Path Evidence Sinks Delay Claim

District of Columbia Court of Appeals

Rustler Construction, Inc. v. District of Columbia

Case no.:    16-AA-1155

Date filed:  July 3, 2019

Overview

A District of Columbia appellate court has ruled that without contemporaneous critical path method (CPM) schedules or after-the-fact expert analysis, a contractor could not prove owner-caused delay to overall project completion.

Background

The District of ... Log in to view the full text.