Article Date: 11/29/2004


NOTICE FAILURE DEFEATS SUBCONTRACTOR'S DELAY CLAIM


North Carolina Court of Appeals

American National Electric Corp., Plaintiff, v. Poythress Commercial Contractors and Brown & Jones Architects, Inc., Defendants

No: COA03-794
November 16, 2004


Background

Poythress Commercial Contractors, Inc. was the general contractor on the Cary Fire Station No. 6 project and American National Electric Corporation (ANE) was an electrical subcontractor. Poythress provided a CPM (critical path method) schedule to ANE ... Log in to view the full text.

 



NOT YET A SUBSCRIBER?

Purchase a Subscription
with a money-back guarantee
and immediate access

Already a member?

Email:  

Password:  











WPL
PUBLISHING CO, INC.
WPL Publishing - 5750 Bou Avenue #1712 - Rockville, MD 20852

Phone: (301)765-9525  -  Fax: (301)983-4367

All Content and Design Copyright © 2024 WPL Publishing
About Us

Contact Us

Privacy Policy

My Account