CONTRACTOR SCHEDULE REVISIONS DID NOT AVOID DEFAULT
U.S. Civilian Board of Contract Appeals
Global Construction, Inc. v. Department of
January 28, 2010
Civilian Board of Contract Appeals has ruled that a contractor's schedule
revisions were insufficient to assure timely completion. And although the
government issued 37 change orders, the contractor received time extensions
covering the cumulative impact on unchanged work.
Department of ... Log in to view the full text.